Standard Terms and Conditions
NOTICE: Sale of any Products or Services is expressly conditioned on Buyer's assent to these Terms and Conditions. Any acceptance of Seller's offer is expressly limited to acceptance of these Terms and Conditions and Seller expressly objects to any additional or different terms proposed by Buyer. Any order to perform work and Seller's performance of work shall constitute Buyer's assent to these Terms and Conditions. Unless otherwise specified in the quotation, Seller's quotation shall expire 30 days from its date and may be modified or withdrawn by Seller before receipt of Buyer's conforming acceptance.
1. Definitions
"Buyer" means the entity to which Seller is providing Products or Services under the Contract.
"Contract" means either the contract agreement signed by both parties, or the purchase order signed by Buyer and accepted by Seller in writing, for the sale of Products or Services, together with these Terms and Conditions, Seller's final quotation, the agreed scope(s) of work, and Seller's order acknowledgement. In the event of any conflict, the Terms and Conditions shall take precedence over other documents included in the Contract.
"Contract Price" means the agreed price stated in the Contract for the sale of Products and Services, including adjustments (if any) in accordance with the Contract.
"Hazardous Materials" means any toxic or hazardous substance, hazardous material, dangerous or hazardous waste, dangerous good, radioactive material, petroleum or petroleum-derived products or by-products, or any other chemical, substance, material or emission, that is regulated, listed or controlled pursuant to any national, state, provincial, or local law, statute, ordinance, directive, regulation or other legal requirements of Canada, the United States ("U.S.") or the country of the Site.
"Insolvent/Bankrupt" means that a party is insolvent, makes an assignment for the benefit of its creditors, has a receiver or trustee appointed for it or any of its assets, or files or has filed against it a proceeding under any bankruptcy, insolvency dissolution or liquidation laws.
“Payment Security” means a bond, irrevocable letter of credit, cash collateral or other similar security acceptable to Seller in an amount approved by Seller in its sole discretion, payable to Seller to guarantee the faithful performance by Buyer of its obligations under this Agreement including the payment of any fees owed under the Contract.
"Products" means the equipment, parts, materials, supplies, software, and other goods Seller has agreed to supply to Buyer under the Contract.
"Seller" means the entity providing Products or performing Services under the Contract.
"Services" means the services Seller has agreed to perform for Buyer under the Contract.
"Site" means the premises where Products are used or Services are performed, not including Seller's premises.
"Terms and Conditions" means these "Terms and Conditions for Sale of Products and Services", including any relevant addenda pursuant to Article 18, together with any modifications or additional provisions specifically stated in Seller's final quotation or specifically agreed upon by Seller in writing.
2. Payment
2.1 Unless otherwise agreed in the quotation, Buyer shall pay Seller for the Products and Services by paying all invoiced amounts, without set-off for any payment from Seller not due under this Contract, within thirty (30) days from the invoice date. For each calendar month, or fraction thereof, that any agreed payment is late, Buyer shall pay a late payment charge computed at the rate of 1.5% per month on the overdue balance, or the maximum rate permitted by law, whichever is less.
2.2 Seller is not required to commence or continue its performance unless and until all agreed progress payments have been received. For each day of delay in receiving progress payments, Seller shall be entitled to a matching extension of the schedule. If at any time Seller reasonably determines that Buyer's financial condition or payment history does not justify continuation of Seller's performance, Seller shall be entitled to require full or partial payment in advance or otherwise restructure payments, request additional forms of payment security, suspend its performance, or terminate the Contract.
3. Taxes and Duties
Seller shall be responsible for all corporate taxes measured by net income due to performance of or payment for work under this Contract ("Seller Taxes"). Buyer shall be responsible for all taxes, duties, fees, and other charges of any nature (including, but not limited to, consumption, gross receipts, import, property, sales, stamp, turnover, use, or value-added taxes, and all items of withholding, deficiency, penalty, addition to tax, interest, or assessment related thereto, imposed by any governmental authority on Buyer or Seller or its subcontractors) in relation to the Contract or the performance of or payment for work under the Contract other than Seller Taxes ("Buyer Taxes"). In the event that Seller is required to collect and remit any Buyer Tax under applicable state law, Seller will add such Buyer Tax to the Contract Price unless Buyer is entitled to an exemption under such applicable state law and provides appropriate documentation in support thereof.
4. Deliveries; Title Transfer; Risk of Loss; Storage
4.1 Unless otherwise agreed in the quotation, Seller shall deliver Products to Buyer EXW Seller's facility or warehouse (Incoterms 2020). Partial deliveries are permitted. Seller, in its sole discretion, may deliver Products in advance of the delivery schedule. Delivery times are approximate and are dependent upon prompt receipt by Seller of all information necessary to proceed with the work without interruption. If Products delivered do not correspond in quantity, type or price to those itemized in the shipping invoice or documentation, Buyer shall so notify Seller within ten (10) days after receipt and if notice has been received within this period, the Seller shall remedy the order in accordance with the invoice or shipping documentation.
4.2 Title to Products shall pass to Buyer upon delivery in accordance with Section 4.1. Notwithstanding the foregoing, Seller grants only a license, and does not pass title, for any software provided by Seller under this Contract, and title to any leased equipment remains with Seller.
4.4 If any Products to be delivered under this Contract or any Buyer equipment repaired at Seller's facilities cannot be shipped to or received by Buyer when ready due to any cause attributable to Buyer or its other contractors, Seller may ship the Products and equipment to a storage facility, including storage at the place of manufacture or repair, or to an agreed freight forwarder. If Seller places Products or equipment into storage, the following apply: (i) title and risk of loss immediately pass to Buyer, if they have not already passed, and delivery shall be deemed to have occurred; (ii) any amounts otherwise payable to Seller upon delivery or shipment shall be due; (iii) all expenses and charges incurred by Seller related to the storage shall be payable by Buyer upon submission of Seller's invoices; and (iv) when conditions permit and upon payment of all amounts due, Seller shall make Products and repaired equipment available to Buyer for delivery.
4.5 If repair Services are to be performed on Buyer's equipment at Seller's facility, Buyer shall be responsible for, and shall retain risk of loss of, such equipment at all times, except that Seller shall be responsible for damage to the equipment while at Seller's facility to the extent such damage is caused by Seller's negligence.
5. Warranty
5.1 Seller warrants that Products shall be delivered free from defects in material, workmanship and title and that Services shall be performed in a competent, diligent manner in accordance with any mutually agreed specifications.
5.2 Subject to the warranty exclusions in Section 5.5, Seller’s warranty for Products shall expire one (1) year from field energization or power-up of the Product or eighteen (18) months from delivery, whichever occurs first. The warranty for Services shall expire one (1) year after performance of the Service.
5.3 If Products or Services do not meet the above warranties, Buyer shall promptly notify Seller in writing prior to expiration of the warranty period. Seller shall (i) at its option, repair or replace defective Products and (ii) re-perform defective Services. If despite Seller's reasonable efforts, a non-conforming Product cannot be repaired or replaced, or non-conforming Services cannot be re-performed, Seller shall refund or credit monies paid by Buyer for such non-conforming Products and Services. Warranty repair, replacement or re-performance shall not extend or renew the applicable warranty period. Buyer shall obtain Seller's agreement on the specifications of any tests it plans to conduct to determine whether a non-conformance exists.
5.4 Buyer shall bear the costs of access for Seller's remedial warranty efforts (including removal and replacement of systems, structures or other parts of Buyer's facility), de-installation, decontamination, reinstallation and transportation of defective Products to Seller and back to Buyer.
5.5 All warranties and remedies set forth herein do not apply to any software embedded or included in the Products; all software is provided AS IS AND WHERE IS. All warranties and remedies set forth herein are conditioned upon (a) proper storage, installation, use, operation, and maintenance of Products, (b) Buyer keeping accurate and complete records of operation and maintenance during the warranty period and providing Seller access to those records, and (c) no modification or repair having been performed on Products or Services except as authorized by Seller in writing. Failure to meet any such conditions renders the warranty null and void. Seller is not responsible for normal wear and tear.
5.6 This Article 5 provides the exclusive remedies for all claims based on failure of or defect in Products or Services, regardless of when the failure or defect arises, and whether a claim, however described, is based on contract, warranty, indemnity, tort/extra-contractual liability (including negligence), strict liability or otherwise. The warranties provided in this Article 5 are exclusive and are in lieu of all other warranties, conditions and guarantees whether written, oral, implied or statutory. EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS SECTION 5, SELLER MAKES NO EXPRESS, IMPLIED OR STATUTORY WARRANTY, WARRANTY OF MERCHANTABILITY, WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE, OR WARRANTY OF NON-INFRINGEMENT.
6. Confidentiality
6.1 Seller and Buyer (as to information disclosed, the "Disclosing Party") may each provide the other party (as to information received, the "Receiving Party") with Confidential Information in connection with this Contract. "Confidential Information" means (a) information that is designated in writing as "confidential" or "proprietary" by Disclosing Party at the time of written disclosure, and (b) information that is orally designated as "confidential" or "proprietary" by Disclosing Party at the time of oral or visual disclosure and is confirmed to be "confidential" or "proprietary" in writing within twenty (20) days after the oral or visual disclosure. In addition, prices for Products and Services shall be considered Seller's Confidential Information.
6.2 Receiving Party agrees: (a) to use the Confidential Information only in connection with the Contract and use of Products and Services, (b) to take reasonable measures to prevent disclosure of the Confidential Information to third parties, and (c) not to disclose the Confidential Information to a competitor of Disclosing Party.
Notwithstanding these restrictions, (a) Seller may disclose Confidential Information to its affiliates and subcontractors in connection with performance of the Contract, (b) a Receiving Party may disclose Confidential Information to its auditors, (c) Buyer may disclose Confidential Information to lenders as necessary for Buyer to secure or retain financing needed to perform its obligations under the Contract, and (d) a Receiving Party may disclose Confidential Information to any other third party with the prior written permission of Disclosing Party, and in each case, only so long as the Receiving Party obtains a non-disclosure commitment from any such subcontractor, auditor, lender or other permitted third party that prohibits disclosure of the Confidential Information and provided further that the Receiving Party remains responsible for any unauthorized use or disclosure of the Confidential Information. Receiving Party shall upon request return to Disclosing Party or destroy all copies of Confidential Information except to the extent that a specific provision of the Contract entitles Receiving Party to retain an item of Confidential Information. Seller may also retain one archive copy of Buyer's Confidential Information.
6.3 The obligations under this Article 6 shall not apply to any portion of the Confidential Information that: (a) is or becomes generally available to the public other than as a result of disclosure by Receiving Party, its representatives or its affiliates; (b) is or becomes available to Receiving Party on a non-confidential basis from a source other than Disclosing Party when the source is not, to the best of Receiving Party's knowledge, subject to a confidentiality obligation to Disclosing Party; or (c) is independently developed by Receiving Party, its representatives or affiliates, without reference to the Confidential Information. In the event that the Receiving Party is required by law or valid legal process to disclose the Confidential Information of the Disclosing Party, the Receiving Party shall promptly notify the Disclosing Party in advance of such disclosure and reasonably cooperate in attempts to maintain the confidentiality of the Confidential Information.
6.4 Each Disclosing Party warrants that it has the right to disclose the information that it discloses. Neither Buyer nor Seller shall make any public announcement about the Contract without prior written approval of the other party. As to any individual item of Confidential Information, the restrictions under this Article 6 shall expire five (5) years after the date of disclosure. Article 6 does not supersede any separate confidentiality or nondisclosure agreement signed by the parties.
7. Intellectual Property
7.1 Seller shall defend and indemnify Buyer against any claim by a non-affiliated third party (a "Claim") alleging that Products or Services furnished by Seller under this Contract infringe a patent in effect in the U.S., an EU member state or the country of the Site (provided there is a corresponding Seller patent issued by the U.S. or an EU member state), or any copyright or trademark registered in the country of the Site, provided that Buyer (a) promptly notifies Seller in writing of the Claim, (b) makes no admission of liability and does not take any position adverse to Seller, (c) gives Seller sole authority to control defense and settlement of the Claim and complies with all reasonable instructions of Seller for the mitigation of damages, and (d) provides Seller with full disclosure and reasonable assistance as required to defend the Claim.
7.2 Section 7.1 shall not apply and Seller shall have no obligation or liability with respect to any Claim based upon (a) Products or Services that have been modified, repaired, or revised, (b) the combination of any Products or Services with other products or services when such combination is a basis of the alleged infringement, (c) failure of Buyer to implement any update provided by Seller that would have prevented the Claim, (d) unauthorized use of Products or Services, or (e) Products or Services made or performed to Buyer's specifications.
7.3 Should any Product or Service, or any portion thereof, become the subject of a Claim, Seller may at its option (a) procure for Buyer the right to continue using the Product or Service, or applicable portion thereof, (b) modify or replace it in whole or in part to make it non-infringing, or (c) failing (a) or (b), take back infringing Products or Services and refund the price received by Seller attributable to the infringing Products or Services.
7.4 Article 7 states Seller's exclusive liability for intellectual property infringement by Products and Services.
7.5 Each party shall retain ownership of all Confidential Information and intellectual property it had prior to the Contract. All new intellectual property conceived or created by Seller in the performance of this Contract, whether alone or with any contribution from Buyer, shall be owned exclusively by Seller. Buyer agrees to deliver assignment documentation as necessary to achieve that result.
8. Indemnity
Each of Buyer and Seller (as an "Indemnifying Party") shall indemnify the other party (as an "Indemnified Party") from and against claims brought by a third party, on account of personal injury or damage to the third party's tangible property, to the extent caused by the negligence of the Indemnifying Party in connection with this Contract. If Buyer is supplying Products or Services to a third party, or using Products or Services at a facility owned by a third party, Buyer shall indemnify and defend Seller from and against any and all claims by, and liability to, any such third party. In the event the injury or damage is caused by joint or concurrent negligence of Buyer and Seller, the loss or expense shall be borne by each party in proportion to its degree of negligence. For purposes of Seller's indemnity obligation, no part of the Products or Site is considered third party property.
9. Insurance
During the term of the Contract, Seller shall maintain for its protection the following insurance coverage: (a) Worker's Compensation, Employer's Liability and other statutory insurance required by law with respect to work related injuries or disease of employees of Seller in such form(s) and amount(s) as required by applicable laws; (b) Automobile Liability insurance with a combined single limit of $2,000,000.00; and (iii) Commercial General Liability or Public Liability insurance for bodily injury and property damage with a combined single limit of $2,000,000.00. If required in the Contract, Seller shall provide a certificate of insurance reflecting such coverage.
10. Excusable Events
Seller shall not be liable or considered in breach of its obligations under this Contract to the extent that Seller's performance is delayed or prevented, directly or indirectly, by any cause beyond its reasonable control, or by armed conflict, acts or threats of terrorism, epidemics, strikes or other labor disturbances, or acts or omissions of any governmental authority or of the Buyer or Buyer's contractors or suppliers. If an excusable event occurs, the schedule for Seller's performance shall be extended by the amount of time lost by reason of the event plus such additional time as may be needed to overcome the effect of the event. If acts or omissions of the Buyer or its contractors or suppliers cause the delay, Seller shall also be entitled to an equitable price adjustment.
11. Termination and Suspension
11.1 Buyer may terminate the Contract (or the portion affected) for cause if Seller (a) becomes Insolvent/Bankrupt, or (b) commits a material breach of the Contract which does not otherwise have a specified contractual remedy, provided that: (i) Buyer shall first provide Seller with detailed written notice of the breach and of Buyer's intention to terminate the Contract, and (ii) Seller shall have failed, within 30 days after receipt of the notice, to commence and diligently pursue cure of the breach.
11.2 If Buyer terminates the Contract pursuant to Section 11.1, (a) Seller shall reimburse Buyer the difference between that portion of the Contract Price allocable to the terminated scope and the actual amounts reasonably incurred by Buyer to complete that scope, and (b) Buyer shall pay to Seller (i) the portion of the Contract Price allocable to Products completed, (ii) lease fees incurred, and (ii) amounts for Services performed before the effective date of termination. The amount due for Services shall be determined in accordance with the milestone schedule (for completed milestones) and rates set forth in the Contract (for work toward milestones not yet achieved and where there is no milestone schedule), as applicable or, where there are no milestones and/or rates in the Contract, at Seller's then-current standard time and material rates.
11.3 Seller may suspend or terminate the Contract (or any affected portion thereof) immediately for cause if Buyer (a) becomes Insolvent/Bankrupt, or (b) materially breaches the Contract, including, but not limited to, failure or delay in Buyer providing Payment Security, making any payment when due, or fulfilling any payment conditions.
11.4 If the Contract (or any portion thereof) is terminated for any reason other than Seller's default under Section 11.1, Buyer shall pay Seller for all Products completed, lease fees incurred and Services performed before the effective date of termination, plus expenses reasonably incurred by Seller in connection with the termination. The amount due for Services shall be determined in accordance with the milestone schedule (for completed milestones) and rates set forth in the Contract (for work toward milestones not yet achieved and where there is no milestone schedule), as applicable or, where there are no milestones and/or rates in the Contract, at Seller's then-current standard time and material rates. In addition, Buyer shall pay Seller a cancellation charge equal to 80% of the Contract Price applicable to uncompleted made-to-order Products and 15% of the Contract Price applicable to all other uncompleted Products.
11.5 Either Buyer or Seller may terminate the Contract (or the portion affected) upon twenty (20) days advance notice if there is an excusable event (as described in Article 10) lasting longer than one hundred and twenty (120) days. In such case, Buyer shall pay to Seller amounts payable under Section 11.4, excluding the cancellation charge for uncompleted Products.
11.6 Buyer shall pay all reasonable expenses incurred by Seller in connection with a suspension, including, but not limited to, expenses for repossession, fee collection, demobilization/remobilization, and costs of storage during suspension. The schedule for Seller's obligations shall be extended for a period of time reasonably necessary to overcome the effects of any suspension.
12. Compliance with Laws, Codes and Standards
12.1 Seller shall comply with laws applicable to the manufacture of Products and its performance of Services. Buyer shall comply with laws applicable to the application, operation, use and disposal of the Products and Services.
12.2 Seller's obligations are conditioned upon Buyer's compliance with all applicable trade control laws and regulations. Buyer shall not trans-ship, re-export, divert or direct Products other than in and to the ultimate country of destination declared by Buyer and specified as the country of ultimate destination on Seller's invoice.
12.3 Notwithstanding any other provision, Buyer shall timely obtain, effectuate and maintain in force any required permit, license, exemption, filing, registration and other authorization, including, but not limited to, building and environmental permits, import licenses, environmental impact assessments, and foreign exchange authorizations, required for the lawful performance of Services at the Site or fulfillment of Buyer's obligations, except that Seller shall obtain any license or registration necessary for Seller to generally conduct business and visas or work permits, if any, necessary for Seller's personnel. Buyer shall provide reasonable assistance to Seller in obtaining such visas and work permits.
13. Environmental, Health and Safety Matters
13.1 Buyer shall maintain safe working conditions at the Site, including, without limitation, implementing appropriate procedures regarding Hazardous Materials, confined space entry, and energization and de-energization of power systems (electrical, mechanical and hydraulic) using safe and effective lock-out/tag-out ("LOTO") procedures including physical LOTO or a mutually agreed upon alternative method.
13.2 Buyer shall timely advise Seller in writing of all applicable Site-specific health, safety, security and environmental requirements and procedures. Without limiting Buyer's responsibilities under Article 13, Seller has the right but not the obligation to, from time to time, review and inspect applicable health, safety, security and environmental documentation, procedures and conditions at the Site.
13.3 If, in Seller's reasonable opinion, the health, safety, or security of personnel or the Site is, or is apt to be, imperiled by security risks, terrorist acts or threats, the presence of or threat of exposure to Hazardous Materials, or unsafe working conditions, Seller may, in addition to other rights or remedies available to it, evacuate some or all of its personnel from Site, suspend performance of all or any part of the Contract, and/or remotely perform or supervise work. Any such occurrence shall be considered an excusable event. Buyer shall reasonably assist in any such evacuation.
13.4 Operation of Buyer's equipment is the responsibility of Buyer. Buyer shall not require or permit Seller's personnel to operate Buyer's equipment at Site.
13.5 Buyer will make its Site medical facilities and resources available to Seller personnel who need medical attention.
13.6. Seller has no responsibility or liability for the pre-existing condition of Buyer's equipment or the Site. Prior to Seller starting any work at Site, Buyer will provide documentation that identifies the presence and condition of any Hazardous Materials existing in or about Buyer's equipment or the Site that Seller may encounter while performing under this Contract. Buyer shall disclose to Seller industrial hygiene and environmental monitoring data regarding conditions that may affect Seller's work or personnel at the Site. Buyer shall keep Seller informed of changes in any such conditions.
13.7 Seller shall notify Buyer if Seller becomes aware of: (a) conditions at the Site differing materially from those disclosed by Buyer, or (b) previously unknown physical conditions at Site differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract. If any such conditions cause an increase in Seller's cost of, or the time required for, performance of any part of the work under the Contract, an equitable adjustment in price and schedule shall be made.
13.8 If Seller encounters Hazardous Materials in Buyer's equipment or at the Site that require special handling or disposal, Seller is not obligated to continue work affected by the hazardous conditions. In such an event, Buyer shall eliminate the hazardous conditions in accordance with applicable laws and regulations so that Seller's work under the Contract may safely proceed, and Seller shall be entitled to an equitable adjustment of the price and schedule to compensate for any increase in Seller's cost of, or time required for, performance of any part of the work. Buyer shall properly store, transport and dispose of all Hazardous Materials introduced, produced or generated in the course of Seller's work at the Site.
13.9 Buyer shall indemnify Seller for any and all claims, damages, losses, and expenses arising out of or relating to any Hazardous Materials which are or were (a) present in or about Buyer's equipment or the Site prior to the commencement of Seller's work, (b) improperly handled or disposed of by Buyer or Buyer's employees, agents, contractors or subcontractors, or (c) brought, generated, produced or released on Site by parties other than Seller.
14. Changes
14.1 Each party may at any time propose changes in the schedule or scope of Products or Services. Seller is not obligated to proceed with any change until both parties agree upon such change in writing. The written change documentation will describe the changes in scope and schedule, and the resulting changes in price and other provisions, as agreed.
14.2 The scope, Contract Price, schedule, and other provisions will be equitably adjusted to reflect additional costs or obligations incurred by Seller resulting from a change, after Seller's proposal date, in Buyer's Site-specific requirements or procedures, or in industry specifications, codes, standards, applicable laws or regulations. However, no adjustment will be made on account of a general change in Seller's manufacturing or repair facilities resulting from a change in laws or regulations applicable to such facilities. Unless otherwise agreed by the parties, pricing for additional work arising from such changes shall be at Seller's time and material rates.
14.3 It shall be acceptable and not considered a change if Seller delivers a Product that bears a different, superseding or new part or version number compared to the part or version number listed in the Contract.
15. Limitations of Liability
15.1 The total liability of Seller for all claims of any kind arising from or related to the formation, performance or breach of this Contract, or any Products or Services, shall not exceed the (i) Contract Price, or (ii) if Buyer places multiple order(s) under the Contract, the greater of (x) the price of each particular order for all claims arising from or related to that order and (y) ten thousand US dollars (US $10,000).
15.2 Seller shall not be liable for loss of profit or revenues, loss of use of equipment or systems, interruption of business, cost of replacement power, cost of capital, downtime costs, increased operating costs, any special, consequential, incidental, indirect, or punitive damages, or claims of Buyer's customers for any of the foregoing types of damages.
15.3 All Seller liability shall end upon expiration of the applicable warranty period, provided that Buyer may continue to enforce a claim for which it has given notice prior to that date by commencing an action or arbitration, as applicable under this Contract, before expiration of any statute of limitations or other legal time limitation but in no event later than one year after expiration of such warranty period.
15.4 Seller shall not be liable for advice or assistance that is not required for the work scope under this Contract.
15.5 For purposes of this Article 15, the term "Seller" means Seller, its affiliates, subcontractors and suppliers of any tier, and their respective employees. The limitations in this Article 15 shall apply regardless of whether a claim is based in contract, warranty, indemnity, tort/extra-contractual liability (including negligence), strict liability or otherwise, and shall prevail over any conflicting terms, except to the extent that such terms further restrict Seller's liability.
16. CANADIAN ORIGINATED SALE
16.1 This Contract shall be interpreted in accordance with and shall be governed by the laws of Province of British Columbia, and the parties agree that any disputes hereunder or with respect to this quotation or resulting contract between the parties shall be determined exclusively by the courts having jurisdiction in the Province of British Columbia, Canada, and the parties hereby expressly at torn to the exclusive jurisdiction of the provincial and federal courts having jurisdiction in the Province of British Columbia.
ARROW USA SALE
16.1 This Contract shall be interpreted in accordance with and shall be governed by the laws of State of Washington, and the parties agree that any disputes hereunder or with respect to this quotation or resulting contract between the parties shall be determined exclusively by the courts having jurisdiction in King County, Washington, and the parties hereby expressly at torn to the exclusive jurisdiction of the state and federal courts having jurisdiction in King County, Washington.
16.2 All disputes arising in connection with this Contract, including any question regarding its existence or validity, shall be resolved in accordance with this Article 16. If a dispute is not resolved by negotiations, either party may, by giving written notice, refer the dispute to a meeting of appropriate higher management, to be held within twenty (20) business days after the giving of notice. If the dispute is not resolved within thirty (30) business days after the giving of notice, or such later date as may be mutually agreed, either party may commence arbitration or court proceedings.
16.3 Notwithstanding the foregoing, each party shall have the right at any time, at its option and where legally available, to immediately commence an action or proceeding in a court of competent jurisdiction, subject to the terms of this Contract, to seek a restraining order, injunction, or similar order to enforce the confidentiality provisions set forth in Article 6 and/or the nuclear use restrictions set forth in Section 19.1, or to seek interim or conservatory measures. Monetary damages shall only be available in accordance with Section 16.2.
17. Inspection and Factory Tests
Seller will apply its normal quality control procedures in manufacturing Products. Seller shall attempt to accommodate requests by Buyer to witness Seller's factory tests of Products, subject to appropriate access restrictions, if such witnessing can be arranged without delaying the work.
18. Software, Leased Equipment, Remote Diagnostic Services, PCB Services
If Seller provides any software to the Buyer; the Software License Addendum shall apply. If Seller leases any of Seller's equipment or provides related Services to Buyer, including placing Seller's equipment at Buyer's site to provide remote Services, the Lease Addendum shall apply. If there is any conflict between these "Terms and Conditions for the Sale of Products and Services, and the terms of any addendum incorporated pursuant to this Article 18, the terms of the addendum shall take precedence with respect to the applicable scope.
19. General Clauses
19.1 Products and Services sold by Seller are not intended for use in connection with any nuclear facility or activity, and Buyer warrants that it shall not use or permit others to use Products or Services for such purposes, without the advance written consent of Seller. If, in breach of this, any such use occurs, Seller (and its parent, affiliates, suppliers and subcontractors) disclaims all liability for any nuclear or other damage, injury or contamination, and, in addition to any other rights of Seller, Buyer shall indemnify and hold Seller (and its parent, affiliates, suppliers and subcontractors) harmless against all such liability. Consent of Seller to any such use, if any, will be conditioned upon additional terms and conditions that Seller determines to be acceptable for protection against nuclear liability.
19.2 Seller may assign or novate its rights and obligations under the Contract, in whole or in part, to any of its affiliates or may assign any of its accounts receivable under this Contract to any party without Buyer's consent. Buyer agrees to execute any documents that may be necessary to complete Seller's assignment or novation. Seller may subcontract portions of the work, so long as Seller remains responsible for it. The delegation or assignment by Buyer of any or all of its rights or obligations under the Contract without Seller's prior written consent (which consent shall not be unreasonably withheld) shall be void.
19.3 Buyer shall notify Seller immediately upon any change in ownership of more than fifty percent (50%) of Buyer's voting rights or of any controlling interest in Buyer. If Buyer fails to do so or Seller objects to the change, Seller may (a) terminate the Contract, (b) require Buyer to provide adequate assurance of performance (including but not limited to payment), and/or (c) put in place special controls regarding Seller's Confidential Information.
19.4 If any Contract provision is found to be void or unenforceable, the remainder of the Contract shall not be affected. The parties will endeavor to replace any such void or unenforceable provision with a new provision that achieves substantially the same practical and economic effect and is valid and enforceable.
19.5 The following Articles shall survive termination or cancellation of the Contract: 2, 3, 4, 5, 6, 7, 8, 10, 11, 12, 13, 15, 16, 18, and 19.
19.6 The Contract represents the entire agreement between the parties. No oral or written representation or warranty not contained in this Contract shall be binding on either party. Buyer's and Seller's rights, remedies and obligations arising from or related to Products and Services sold under this Contract are limited to the rights, remedies and obligations stated in this Contract. No modification, amendment, rescission or waiver shall be binding on either party unless agreed in writing.
19.7 Except as provided in Article 15 (Limitations of Liability) and in Section 19.1 (no nuclear use), this Contract is only for the benefit of the parties, and no third party shall have a right to enforce any provision of this Contract.
19.8 This Contract may be signed in multiple counterparts that together shall constitute one agreement.